Page:United States Statutes at Large Volume 92 Part 2.djvu/1105

From Wikisource
Jump to navigation Jump to search
This page needs to be proofread.

PUBLIC LAW 95-000—MMMM. DD, 1978

PUBLIC LAW 95-563—NOV. 1, 1978

92 STAT. 2385

authorized by this Act. Nothing in this Act shall prohibit executive agencies from including a clause in government contracts requiring that pending final decision of an appeal, action, or final settlement, a contractor shall proceed diligently with performance of the contract in accordance with the contracting officer's decision. (c)(1) A contracting officer shall issue a decision on any submitted claim of $50,000 or less within sixty days from his receipt of a written request from the contractor that a decision be rendered within that period. For claims of more than $50,000, the contractor shall Certification, certify that the claim is made in good faith, that the supporting data are accurate and complete to the best of his knowledge and belief, and that the amount requested accurately reflects the contract adjustment for which the contractor believes the government is liable. (2) A contracting officer shall, within sixty days of receipt of a submitted certified claim over $50,000— (A) issue a decision; or (B) notify the contractor of the time within which a decision Notification, will be issued. (3) The decision of a contracting officer on submitted claims shall be issued within a reasonable time, in accordance with regulations promulgated by the agency, taking into account such factors as the size and complexity of the claim and the adequacy of the information in support of the claim provided by the contractor. (4) A contractor may request the agency board of contract appeals to direct a contracting officer to issue a decision in a specified period of time, as determined by the board, in the event of undue delay on the part of the contracting officer. (5) Any failure by the contracting officer to issue a decision on a •• contract claim within the period required will be deemed to be a decision by the contracting officer denying the claim and will authorize the commencement of the appeal or suit on the claim as otherwise provided in this Act. However, in the event an appeal or suit is so commenced in the absence of a prior decision by the contracting officer, the tribunal concerned may, at its option, stay the proceedings to obtain a decision on the claim by the contracting officer. CONTRACTOR S RIGHT OF APPEAL TO BOARD OF CONTRACT APPEALS

SEC. 7. Within ninety days from the date of receipt of a contract- 41 USC 606. ing officer's decision under section 6, the contractor may appeal such decision to an agency board of contract appeals, as provided in section 8. AGENCY BOARDS OF CONTRACT APPEALS

SEC. 8. (a)(1) Except as provided in paragraph (2) an agency board of contract appeals may be established within an executive agency when the agency head, after consultation with the Administrator, determines from a workload study that the volume of contract claims justifies the establishment of a full-time agency board of at least three members who shall have no other inconsistent duties. Workload studies will be updated at least once every three years and submitted to the Administrator. (2) The Board of Directors of the Tennessee Valley Authority may establish a board of contract appeals for the Authority of an indeterminate number of members. (b)(1) Except as provided in paragraph (2), the members of agency boards shall be selected and appointed to serve in the same manner as

Establishment, consultation, ^^ ^SC 607.

Membership,