Grant v. United States (74 U.S. 331)

by David Davis

United States Supreme Court

74 U.S. 331

Grant  v.  United States

APPEAL from the Court of Claims; in which court Grant, for himself, and as assignee of one Taliafero, a former partnor, had filed a petition claiming reimbursement and damages from the United States. The case was this:

On the 9th of March, 1860, the Secretary of War, at that time Mr. Floyd, addressed an order to the Quartermaster-General and Commissary-General of Subsistence, granting to the said Taliafero and Grant the privilege of furnishing and delivering, at certain posts in Arizona, for a period of two years, all the supplies that might be needed there for the use of the service, at certain stipulated rates. There was nothing in this order making an inspection necessary elsewhere than at the place of delivery.

On the 29th of July, 1860, the proper officer in Arizona served a requisition on Grant for commissary articles, and the War Department approved the order on the 22d day of September following, with notice that the articles to be purchased would be inspected at Boston or New York.

Some delays took place in regard to the inspection; for the appointment of a proper person to make which, the shipping agents of Grant had made a request on the 20th September, 1862. Major Eaton finally inspected the last of the supplies, certifying that they were contained in strong, sound, full-hooped barrels and well-secured tierces, properly marked with the names of the places to which they were destined, and were of the kind and quality usually provided by the subsistence department. This inspection did not take place until the 3d, 4th, 5th of December, 1860. The Court of Claims found, however, as facts, that the only delay attributable to the United States was a delay in appointing an inspector from the 22d September to the 21st November, 1860; that such delay did not preclude Grant's agents from purchasing the supplies required, and having them ready for inspection; that the supplies inspected by Major Eaton were sold to Grant on the 20th of November, 1860; that the United States were ready to inspect supplies on the 21st of November, 1860, and thereafter, and on that date so notified to Grant's agents; that the inspection was not made at that time, but was postponed at the request of the said agents from the difficulty they had found in procuring a part of the supplies; that these were not then ready for shipment and inspection; that there was no evidence of any notice to the United States to make inspection other than one contained in a letter of the agents to Major Eaton, dated November 22d, 1860.

The supplies thus inspected were immediately afterwards shipped to Lavacca, and arrived there about the 10th January, 1861. They were here laden on wagons, forty-one wagons in all, but after proceeding a short distance, the train was obliged, owing to want of pasturage at that season of the year, to stop and go into camp and await the growth of grass. A delay was thus incurred of about two months and ten days, when the train again proceeded, and arrived at Rio Honde, where it was captured on the 20th April by the troops of Texas, then in a state of rebellion against the United States.

For the goods, wagons, and teams thus lost, the petitioners claimed reimbursement.

The petition also set forth great loss to the petitioner, asking damages for it, from the fact that while, as alleged, he was in the due execution of his contracts, and actually engaged in the transportation of supplies from Lavacca to Arizona, the United States, of its own wrong, and without any fault or negligence on his part, and without notice to him, and without his agreement or consent, had set aside and rescinded the said contracts. On this part of the case it appeared that in April, 1861, the Assistant Commissary-General had recommended to Mr. Cameron, by this time Secretary of War, that the contracts 'be rescinded,' and that, from a sense of insecurity, certain of the articles should be forwarded from St. Louis, and that others might be procured in Arizona or Sonora, of those persons who would furnish them at the cheapest rates. The secretary approving the order, the contract was no longer regarded by the United States as valid.

The Court of Claims dismissed the petition, and the claimant appealed.

Mr. C. B. Gooderich, for the appellant:

I. The petitioner submitted to and acted upon the direction to inspect at Boston and New York. That it was competent for the secretary and the petitioner to agree to inspect at those places, and, to that extent, to modify the terms of the original order, there can be no doubt. The petitioner having acted upon it, pro tanto, to government cannot be allowed to say it was not obligatory upon him. The fact, if it were a fact, that the direction of the War Department for the inspection in Boston and New York, was for the benefit of the contractor, cannot destroy his rights under the modification of the contract.

The inspection by Major Eaton, his acceptance thereof, as shown by his certificate, passed the title in and to the goods inspected and marked.

After inspection and marking, the goods remained in the possession of the claimant but for transportation. The completion of this was prevented by the public enemy, and consequently the loss must be borne by the government. The capture of the goods by an armed force, in rebellion, acting with intent to subvert the government, under the facts found in the case, is a delivery to the United States of the goods ordered.

The relation of the parties, the purpose of the seizure made by the enemy, the use for which the supplies were intended, taken in connection with the fact that the petitioner, as a contractor with the government, must be regarded as in its service, and was rightfully in the face of the enemy, conduce to show that the capture, in this case, by an armed enemy of the government, stands upon grounds peculiar and distinct from those which may or may not apply to a capture from a contractor under other circumstances.

Upon principle, in all cases in which private property is seized by a public enemy, without any default of the owner, the government is bound to sustain the loss. Vattel ^[1] concedes the principle, although he adds, 'that no action lies against the state for misfortunes of this nature.' He denies but the remedy. He says that 'the sovereign, indeed, ought to show an equitable regard for the sufferers, if the situation of his affairs will admit of it.'

II. The rescission of the contract, by Secretary Cameron, without cause shown, and in the absence of any default on the part of the petitioner, entitles him to damages, which are to be determined by an ascertainment of the profits which he would have made if the contract had not been rescinded, or by a consideration of the expenses which the petitioner had incurred in obtaining teams, &c., to enable him to execute his contract.

Mr. Dickey, Assistant Attorney-General, contra, contended:

I. That the claim for the loss of private property taken in war by the enemy, could not be sustained on principles of law, and was no such claim as the Court of Claims has jurisdiction to try and allow.

That the inspection of goods of a contractor thousands of miles from the place of delivery, did not vest the property so inspected in the United States.

That the whole claim for the loss by capture rested upon the position, that this resulted, without the fault of claimant, from delays caused by the culpable neglect of the United States to inspect the goods at an earlier day; but that the facts did not sustain the claim.

II. As to the rescission. That assuming that the order of Secretary Floyd was a contract, it nowhere appeared that any such supplies were needed after the rescinding of the order. The rescinding of it, therefore, was after the full execution of it, inasmuch as all the supplies needed, &c., had already been furnished, and nothing remained to be done under the order, or if it were a contract, under the contract.

Mr. Justice DAVIS delivered the opinion of the court.

Notes

1. Law of Nations, p. 403.